Welcome to Ramana Interiors. By accessing or using our website and services, you agree to comply with and be bound by the following Terms and Conditions. Please read them carefully before proceeding.
1. General Information
Ramana Interiors provides interior design, modular kitchen, wardrobe, TV unit, and related services. By engaging with our services, you accept these terms in full. If you do not agree with any part, please discontinue use of our website or services.
2. Services
- All designs, layouts, and concepts provided by Ramana Interiors are customized as per client requirements.
- Timelines for completion may vary depending on project scope, material availability, and client approvals.
- Prices and quotations are subject to change based on final design, material selection, and additional requests.
3. Payments
- A percentage of the project cost will be collected as advance payment to initiate work.
- Remaining payments must be made as per the mutually agreed schedule.
- Delayed payments may result in project delays or suspension of work until payment is received.
4. Materials & Warranty
- We source materials from trusted vendors and ensure quality standards.
- Warranties on products (if applicable) are subject to manufacturer policies.
- Ramana Interiors is not liable for damages caused by misuse, wear & tear, or external factors after installation.
5. Modifications & Cancellations
- Any design or material changes requested after project initiation may affect timelines and overall cost.
- Project cancellations after commencement will be subject to deductions for work completed, materials purchased, and services rendered.
6. Limitation of Liability
- While we strive for accuracy and quality, Ramana Interiors will not be held responsible for unforeseen delays, third-party issues, or circumstances beyond our control.
- We are not liable for indirect, incidental, or consequential damages arising from project delays or service usage.
7. Intellectual Property
- All designs, layouts, images, and content shared by Ramana Interiors remain our intellectual property unless otherwise agreed in writing.
- Clients may not reproduce, distribute, or share our design concepts without prior permission.
8. Governing Law
These Terms & Conditions shall be governed by and construed in accordance with the laws of India. Any disputes will fall under the jurisdiction of the courts in [Your City, India].
9. Contact Us
For questions or clarifications regarding these Terms & Conditions, please contact us:
📧 Email: connect@ramanainterior.com
📞 Phone: +91 9381505728
